Or. Admin. Code § 137-049-0810 - Waiver of Delay Damages Against Public Policy
Contracting Agencies shall not place any provision in a Public Improvement Contract purporting to waive, release, or extinguish the rights of a Contractor to damages resulting from a Contracting Agency's unreasonable delay in performing the Contract. However, Contract provisions requiring notice of delay, providing for alternative dispute resolution such as arbitration (where allowable) or mediation, providing other procedures for settling contract disputes, or providing for reasonable liquidated damages, are permissible.
Notes
Stat. Auth.: ORS 279A.065
Stats. Implemented: ORS 279C.315
State regulations are updated quarterly; we currently have two versions available. Below is a comparison between our most recent version and the prior quarterly release. More comparison features will be added as we have more versions to compare.